Terms & Conditions

Terms and Conditions

Effective Date: September 2025 Welcome to JDH Carpentry & Construction ("we", "us", or "our"). These Terms and Conditions ("Terms") govern your use of our website jdhcarpentry.com.au and any we provide, including carpentry and construction contracting. By accessing our website or utilising our, you agree to comply with these.

1. Services

We provide a variety of carpentry construction services throughout Sydney, including residential and commercial, renovations, fit-outs, and maintenance work. Each project will be governed by a separate written agreement or quote.

2. Quotes and Estimates

Any quotes or cost estimates provided via our website, email or phone are non-binding until written confirmation and acceptance by parties. Final costs may vary based on site conditions, in scope, material availability, or other factors.

3. Client Responsibilities

Clients are responsible: - Providing accurate and complete project and property information. - Ensuring access to the job site and necessary permissions or approvals. - Making timely payments according to the agreed schedule. Delays or stemming from unmet responsibilities may affect project timelines and costs.

4. Payments

Payment terms are in individual service or invoices. All payments must be made according the provided schedule. Late payments may incur interest and could lead to work delays suspension. Accepted payment methods: [Specify if applicable—e.g., bank transfer, EFT, etc.]

5. Warranty and Liability

We guarantee our workmanship for a period of [e.g., 12 months] from the completion date unless stated otherwise in contract. We are not liable for- Damage caused by third parties or alterations made after project completion. - Delays due to weather, material shortages, or client-related delays. - Indirect, incidental or consequential damages.

6. Intellectual Property

All content our website (texts,, logos, and designs) is owned by JDH Carpentry & Construction its content providers. Reproduction,, or use of our content without written permission is prohibited.

7. Privacy

Your use of our website is also governed by our Privacy Policy, which details how we collect, store, and protect your personal information. A copy can be via the email address below.

8. Third-Party Links

Our website may contain links to third-party websites or services. JDHentry & Construction is not responsible for their content, accuracy, or practices.

9. Termination of Use

We reserve the right to or restrict access our website or services at any time if we believe you have violated these Terms.

10. Governing Law

These Terms are governed by the laws of New South Wales, Australia. Any disputes arising from or related to Terms will be resolved in the courts of NSW.

11. To Terms

We may update these Terms periodically. Updates will be posted on this page with a new effective date. Continued use of our website or services indicates acceptance of the updated Terms. .

For any or concerns regarding these Terms, please reach out to us

JDH Carpentry & Construction

Location: Sydney, NSW, Australia

Phone: 0421 806 998

Email: info@jdhcarpentry.com.au

Website: www.jdhcarpentry.com.au